The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under .section 3703 of title 40
Title 28
This is not an official government website.
© 2026 PLEJ LC. All rights reserved.
Title 28
Liquidated damages withheld from contractors under chapter 37 of title 40
Need the full chapter outline? Open Chapter 91 to browse every section without loading the entire chapter explorer on this page.
The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under .section 3703 of title 40